Loading...
Serving Compton, CA and surrounding areas. (424) 447-1306
Effective date: January 1, 2026
By accessing our website at comptonsunroomcontractor.com or by requesting services from Compton Sunrooms & Patios, you agree to be bound by these terms and conditions. If you do not agree with any part of these terms, do not use our website or engage our services.
Compton Sunrooms & Patios provides sunroom additions, patio enclosures, screen room installations, and related outdoor living improvements to residential properties. Services are provided in Compton, CA and surrounding communities. All work is performed by or under the supervision of licensed and insured personnel. Specific services, scope, and materials are defined in a written contract signed by both parties before work begins.
Free on-site estimates are provided without obligation. A written estimate reflects the scope of work as understood at the time of the site visit. Estimates are not binding contracts.
A formal written contract will be provided before any work begins. The contract price is the agreed price for the scope of work described in it. Changes to scope requested by the client after contract signing will be handled through a written change order, which will specify any additional cost or credit and must be signed by both parties before the additional work is performed.
Unforeseen site conditions discovered during construction - such as foundation issues, hidden structural damage, or utility conflicts - may require additional work and cost. We will notify you promptly and provide a written change order before proceeding with any out-of-scope work.
Start dates and completion timelines provided are estimates. Construction timelines can be affected by factors outside our control, including permit processing times, weather, material availability, and inspection scheduling. We will communicate any material delays to you as soon as we are aware of them.
The client is responsible for ensuring the work area is accessible and cleared of personal property before the scheduled start date. Delays caused by the client may result in a revised schedule.
Either party may cancel a contract before construction begins by providing written notice. If you cancel after a deposit has been paid but before work starts, you may forfeit some or all of that deposit to cover costs already incurred, including permit fees, material orders, and scheduling commitments. The specific terms will be stated in your written contract.
Once construction has begun, cancellation may result in payment for all work completed to the point of cancellation plus reasonable costs for materials already ordered or installed.
Payment terms are set out in your written contract. A deposit is typically required to begin the permit process and schedule your project. Progress payments may be required at specified milestones. Final payment is due upon substantial completion of the work, before final permit sign-off documentation is transferred.
Accepted payment methods are described in your contract. Invoices not paid by the due date stated in the contract may accrue a late fee as specified in the contract.
Pursuant to California law, a contractor may not collect a deposit exceeding 10 percent of the contract price or $1,000, whichever is less, before the work begins - except in specific limited circumstances. Your contract will comply with applicable California law.
Compton Sunrooms & Patios is responsible for obtaining required building permits for the contracted scope of work and for scheduling required inspections. Permit fees are typically included in the contract price unless otherwise stated. You will receive copies of all permit documents and final inspection sign-offs upon project completion. Work performed under a building permit that passes final inspection is legally documented and transferable to future owners.
Compton Sunrooms & Patios warrants that work will be performed in a workmanlike manner consistent with industry standards and the scope defined in your written contract. Specific warranty terms, duration, and coverage are set out in your contract.
Materials and products used in your project may carry manufacturer warranties separate from our workmanship warranty. We will provide you with any available manufacturer warranty documentation at project completion.
Warranties do not cover damage caused by misuse, neglect, modifications made by others, acts of nature, or normal wear and tear. Our website and any general marketing content are provided on an "as is" basis without warranties of any kind.
To the fullest extent permitted by applicable law, Compton Sunrooms & Patios shall not be liable for any indirect, incidental, special, or consequential damages arising out of or related to the use of our website or the performance of our services, including loss of use, loss of business, or loss of income, even if we have been advised of the possibility of such damages.
Our total liability for any claim arising out of or related to the services provided shall not exceed the amount paid by the client for the specific work giving rise to the claim.
The client is responsible for:
All content on our website, including text, images, and design, is the property of Compton Sunrooms & Patios or its licensors. You may not reproduce, copy, or distribute any content from this site without our prior written permission.
If a dispute arises between you and Compton Sunrooms & Patios, we encourage you to contact us directly first to resolve it. Most issues can be addressed through open communication, and that is always our first preference.
If we cannot resolve a dispute informally, both parties agree to attempt mediation before pursuing any legal action. Any legal proceedings that are not resolved through mediation shall be brought in the courts of Los Angeles County, California.
These terms and conditions are governed by and construed in accordance with the laws of the State of California, without regard to its conflict of law provisions. Any disputes arising under these terms shall be subject to the exclusive jurisdiction of the courts located in Los Angeles County, California.
We may update these terms from time to time. When we do, we will update the effective date at the top of this page. Continued use of our website after any changes constitutes your acceptance of the updated terms. Changes do not affect the terms of any written contract already signed by both parties.
If you have questions about these terms, contact us: